Department Of Water Resources- Punjab Water Resources Management And Development Corporation- De - Lining Division No. - 8 - Bathinda - Agency Tenders

The bid notice states that he approximate time for completion of the work will be 180 days as desired by executive engineercumengineerincharge after the date of issue of work order or acceptance letter to the contractor.

Payments of work done shall be released on receipt of funds from the government of punjabrealisation of loc from the concerned treasury and no interest claim will be entertained on delayed payments.

The eligibility criteria are defined in the eligibility for participation for single tier system and conditions for participation for two tier system.

The tenderer will follow the instructionsrules for loading of material. He will have to follow strictly the carriage load capacity rules or any instructions issued by transport department from time to time, failing which penalty shall be levied on account of carriage of material by recovery @50 from the bill of the contractoragencylc society.

Before filling this tender the contractor can see the detailed drawings and specifications in the office of the divisional engineer, lining division no. 08, bathinda on any working day during working hours and shall visit the site and satisfy himself as to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of tools and plants etc.

The successful bidder shall have to provide vehicle within a period of one month from the date of the signing of the contract. The period can, however, be extended by one month with the concurrence of the competent authority.

The monthly cash consideration amount as quoted in the financial bid is minimum guaranteed payment which will be paid to the bidder per month irrespective of the mileage operated by the vehicle subject to the maximum. of **** k. m. per month. The annual increase in the rent of the vehicle shall be made as per decision taken by the department of transport in this regard.

The bidder who quotes the lowest amount of the monthly cash consideration in the financial bid performa at annexureiii of this tender document shall be declared as the successful bidder.

A. In case of breach of any conditions of the contract and for all type of losses caused including excess cost due to hiring of car from the market in the event of applicant failing to provide requisitioned number of cars or not providing cars. The office shall make deductions at the rate of hiring rate on prorata basis from the bills preferred by the applicant or that may become due to the applicant under this or any other contract or from the security deposit or may be demanded from him to be paid within seven days to the credit of the divisional engineer, bathinda pwrmdc division, bathinda. B. The powers of the competent authority under this condition shall in no way affect or prejudice the powers in certain events to terminate the contract vested in him as herein provided nor forfeiture of deposit mentioned under clause 24 and 27 above.

The last date and time for receipt of bids is **** 10:00 hours.

Payments of work done shall be released on receipt of funds from the government of Punjab/realisation of LOC from the concerned treasury and no interest claim will be entertained on delayed payments.

Only those contractors registered with the Punjab Water Resources Department and having deposited the requisite licensing fee are eligible. Bidders must have successfully completed at least two major works of similar nature valuing not less than the amount of work of this tender, during the last three consecutive calendar years. A documentary proof issued by an officer not below the rank of executive engineer of the concerned department should be attached.

Penalty shall be levied on account of carriage of material by recovery @50 from the bill of the contractor/agency/LC society, if the instructions/rules for loading of material are not followed.

The contractor can see the detailed drawings and specifications in the office of the divisional engineer and shall visit the site and satisfy himself as to the conditions prevalent there.

Any dispute shall have to be referred to the arbitrator within two weeks after the final payment and no claim shall be entertained thereafter.

The tentative estimated cost for the lining/relining of watercourses is 1,10,097.

The last date for receipt of bids is 18 September 2025 at 10:00 hours.

Payment will be released on receipt of funds from the government.

Only contractors registered with the Punjab Water Resources Department and having completed at least two major works of similar nature in the last three consecutive calendar years will be eligible.

Penalty shall be levied on account of carriage of material by recovery @50 from the bill of the contractor.

The contractor can see the detailed drawings and specifications in the office of the divisional engineer and visit the site to satisfy himself about the conditions.

Any dispute shall have to be referred to the arbitrator within two weeks after the final payment.

The estimated cost for the lining/relining of watercourses of outlet rd **** is 1,10,00,000.

The bid notice states he approximate time for completion of the work will be 180 days as desired by executive engineercumengineerincharge after the date of issue of work order or acceptance letter to the contractor.

The bid notice states payments of work done shall be released on receipt of funds from the government of punjabrealisation of loc from the concerned treasury and no interest claim will be entertained on delayed payments.

The bid notice states he final acceptance of the tenders or part of the same lies with the competent authority who does not bind himself to accept the lowest or any other tender without assigning any reason for the same.

The bid notice states only those contractors shall be eligible who are registered with punjab water resources, departmentpwrmdc and have deposited the requisite licensing fee. bid document shall only be sold to those contractorsagencieslc societies who have registered themselves with our service provider to participate in tenders and should have bank accounts with core banking solution branches with neftrtgs facility. contractorsconsortiums who have successfully completed at least two major works of similar nature valuing not less than the amount of work of this tender, during the last three consecutive calendar years, shall only be considered. a documentary proof issued by an officer not below the rank of executive engineer of the concerned department should be attached.

The bid notice states if the material does not meet the required specification and the same is not removed by the contractor then it shall be removed from site of work at the risk and cost of the contractor. penalty shall be levied on account of carriage of material by recovery @50 from the bill of the contractoragencylc society.

The bid notice states before filling this tender the contractor can see the detailed drawings and specifications in the office of the divisional engineer, lining division no. 08, bathinda on any working day during working hours and shall visit the site and satisfy himself as to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of tools and plants etc. accommodation and movement of labour, supply of water and power for satisfactory completion of the works.

The bid notice states any dispute as stated above shall have to be referred to the arbitrator within two weeks after the final payment and no claim shall be entertained thereafter.

The bid notice states 1, 10, 00, 000