Hand Truck e-Tenders

Supply is to be done within 14 weeks from the date of po. supply 14 weeks from date of po.

For indigenous offers, 80% of the supply value will be paid within 45 days from the date of receipt of material at bhel, subject to gr clearance, and the balance 20% after successful commissioning. supply and ec to be done by vendor 80 payment of supply value will be made within 45 days from the date of receipt of material at bhel subject to gr clearance. balance 20 of supply value

The required guarantee period is 24 months from the date of material acceptance. guarantee warranty period required: 24 months from the date of material acceptance.

Evaluation is done item-wise. evaluation is itemwise.

Bidders must submit specification drawings, technical offer, and standard commercial terms. bidder shall be submit specificationdrawingspqc documents duly signed and stamped along with technical offer.

The rate of penalty for delayed supply shall be at the rate of 0. 5 per week of delay of total po value supply installation in supply subject to max. of 10 of total po value supply installation. rate of penalty for delayed supply shall be at the rate 0. 5 per week of delay of total po value supply installation in supply subject to max. of 10 of total po value supply installation.

Inadequate, incomplete, ambiguous, or unsustainable information against any of the clauses of the specifications requirements shall be treated as noncompliance. inadequate incomplete, ambiguous, or unsustainable information against any of the clauses of the specifications requirements shallbe treated as noncompliance.

The last date and time for online submission of completed tender documents is up to 9:00 AM on August 24, 2026.

Payment will be made by OSCSC on submission of bills, normally within 30 days of submission of a complete set of bills. Payment will be made through the PFMS platform.

Tenders will be assessed on the basis of least cost based selection (LCBS). The financial bids of technically qualified bidders will be opened, and the L1 bidder will be the preferred bidder.

Bidders must furnish a bank certificate indicating financial capability of at least Rs. 50 lakhs, experience in rake handling or transportation with an average annual turnover of Rs. 1 crore in the preceding three financial years, and an affidavit declaring no criminal conviction or pending cases.

Liquidated damages may be levied for delays, and the security deposit can be forfeited in case of non-performance, breach of contract, or failure to submit documents.

Bidders may be disqualified if they have a commercial interest in custom milling for OSCSC, have been blacklisted, convicted by a court, or if their contract with OSCSC has been terminated previously.

The last date and time for online submission of completed tender documents is August 24, 2026, up to 9:00 AM.

Payment will be made by OSC on submission of bills, in triplicate, duly supported by consignee receipts or work certificates. Bills should be submitted not later than two months from the contract expiry. Payment is normally made within 30 days of submission of complete bills.

Tenders will be assessed on a least cost based selection (LCBS) system. The financial bids of technically qualified bidders will be opened, and the L1 bidder will be the preferred bidder.

Bidders must have a financial capability certificate of at least Rs. 50 lakhs from a nationalized or scheduled bank. They must also have experience in rake handling or transportation with an average annual turnover of Rs. 1 crore in the preceding three financial years. A minimum of 5 heavy vehicles with GPS enabled vehicle location tracking devices are required.

Liquidated damages may be levied for delay at Rs. 100 per day per quintal or part thereof, not exceeding 50% of the contract value. For transit shortage beyond 0. 17%, the contractor is liable to pay at twice the average acquisition cost.

Bidders may be disqualified if they have a commercial interest in custom milling for OSC, have been blacklisted, convicted by a court, or had their contract terminated by OSC in the past. Failure to submit required documents will also lead to rejection.

The last date and time for online submission of completed tender documents is up to 9:00 AM on August 24, 2026.

Payment will be made by OSCSC on submission of bills in triplicate, duly supported by consignee receipts or work certificates. Bills should be submitted within two months from the contract expiry date. Payment will normally be made within 30 days of submission of complete bills.

Tenders will be assessed in accordance with the least cost based selection (LCBS) system. The financial bids of technically qualified bidders will be opened, and the L1 bidder will be the preferred bidder.

Bidders must have a financial capability certificate of at least Rs. 50 lakhs from a nationalized or scheduled bank. They must also have experience in rake handling or transportation of foodgrains or similar commodities with an average annual turnover of Rs. 1 crore in the preceding three financial years. A minimum of 5 heavy vehicles with GPS enabled vehicle location tracking devices are required.

Liquidated damages may be levied for delays in providing labor, trucks, or services. The decision of the Managing Director on the quantum of damages is final. Loss or damage to goods in transit beyond admissible shortage will be recovered from the contractor.

The document does not mention any requirement for sample submission.

Tenders may be rejected if not accompanied by the required EMD, if false information is furnished, or if the bidder has been blacklisted or convicted by a court of law. Failure to submit any prescribed document will result in rejection.