Asphalt Inspection e-Tenders

The tender is for special repair work on roads in Bagpat district. Bids must be submitted online by 05122025. Technical bids will be opened on **** pre-bid meeting is scheduled for 29112025. The bid validity is 90 days. Registration on the website is mandatory. Original documents must be submitted after the technical and financial bids are opened. A bid security is required. The work must be completed according to the schedule.

The tender is for renovation, construction, and pavement work in Varapatti Panchayat. The bid submission end date is November 11, 2025, at 3:00 PM. The bid opening date is November 11, 2025, at 4:00 PM. Documents required include IT certificate, revenue solvency certificate, PAN details, GST certificate, profit and loss statement, and work completed certificate copies. EMD is required.

The tender for the construction of a lane drain in Marheen requires separate technical and financial bids submitted online by the deadline of September 2, 2025. The technical bid will be opened in the presence of the evaluation committee, and the financial bid will be opened only for qualified bidders. Bids must include the priced bill of quantities, using item rates, and all applicable taxes and duties. The earnest money, in the form of CDR/FDR, must be valid for six months after the last date of bid receipt. The successful bidder's performance security will be released after the defect liability period. The tender documents must be submitted by the schedule date and time. The employer may extend the deadline for submission of bids by issuing an amendment. The employer will open the bids in the presence of bidders' representatives. If the submission date is a holiday, the bids will be opened on the next working day. The bid validity period is 120 days after the deadline date for bid submission. The department reserves the right to accept or reject any or all tenders. The work must be completed within the stipulated time period; otherwise, a penalty of up to 10% of the total value of the work may be imposed. For any dispute, the Chief Engineer will act as an arbitrator. The jurisdiction of the Jammu court will be applicable. The department will deduct 1% cess on the cost of construction and deposit it with the JK Building and other Construction Workers Welfare Board. Service tax will be deducted as applicable. The use of a vibrator is mandatory for all concrete works. The quantities advertised are approximate and can be increased or decreased by 20% as per necessity at site. Any additional items found necessary during execution will be paid as per the sanctioned schedule of rates. Any items not necessary will be deleted. The watch and ward of all materials and machinery shall be the responsibility of the contractor agency. No extra lead, lift, or carriage will be paid other than what has been advertised in the rate list. The intending contractors/agencies are advised to inspect the site of work and keep in view the actual conditions prevailing at site before tendering for the work. Nothing extra shall be paid on account of loading/unloading of material at the site of work. The work shall have to be completed by the contractor within the stipulated time period mentioned above and in case of his failure penalty to the extent of 10 of the total value to the work shall be imposed upon him at the discretion of the next higher allotting authority. In case of work allotted by the chief engineer, the decision of the penalty will also be taken by the chief engineer himself. The material including asphalt issued to the contractor but found short will be recovered from the deposit bills of the contractor at one-and-a-half-time stock rates of the department. All terms and conditions of the NIT/agreement/special conditions laid down in the enclosed rate list shall also hold good. The department shall deduct the 1% cess on cost of construction and deposit the same with the JK building and other construction workers welfare board labour department under the provision of law in order to avoid any legal proceedings. Service tax shall be deducted as applicable under rule. Time of completion is the essence of tender. After the completion of allotted date, the work will be put to fresh tender at what stage it may be at the risk and cost of the tenderer. The work shall have to be completed by the contractor within stipulated time period mentioned above and in emergency cases, if work allowed to continue beyond expiry period, then the current stock rate of key construction material shall be applicable rather than the advertised in the nit. Use of vibrator is mandatory for all concrete works. Test reports of concrete/bituminous works are required.

Tenders are invited for various construction works in Jammu and Kashmir. Approved and eligible contractors registered with the UT of JK govt. , CPWD, Railways, and other state/central governments can participate. The tender documents, including prequalification criteria, eligibility restrictions, specifications, and bill of quantities, are available on the departmental website. Bidders must submit their bids online with a digital signature. The final date for submission of proposals is 20250908. The tender opening date is **** security may be required for unbalanced bids. Successful bidders will submit performance security. The estimated total value of the tender is INR 290,000. The tender is open to startups and MSMEs for repair contracts up to INR **** lacs. The tender documents must be uploaded between the bid submission start date and end date. The bidder must have easy access to his contact information. The L1 bidder must submit the affidavit in original at the time of submission of tender documents. The bidder at his own responsibility and risk should visit and examine the site of work and its surroundings before submission of bid. All documents relating to the bid shall be in the English language. The departmental material shall be supplied to the contractor at stock rate. The bidder shall quote the rates for items of the work in a balanced way. The date of start of the works shall be reckoned within one week from the date of issuance of LOI. No child labour shall be engaged. Penalty for delay in completion of work beyond the stipulated period of completion, penalty up to a maximum of 10% of the contract shall be imposed. Time extension may be granted in case of increase in scope of work and delay beyond the contractor's control. Retention money of 10% shall be deducted from each running bill of the successful contractor. The payments schedule shall be fixed after award of contract. Amendments to the bidding documents may be issued by the employer before the deadline for submission of bids. The tender receiving authority reserves the right to accept or reject any or all tenders or any part of any tender without assigning any reason thereof. Restoration of work, traffic regulations, arbitration, defect liability period, safety, discoveries, tests, termination, major labour laws applicable to establishment engaged in building and other construction work, specification, quality control, insurance, laws governing the contract, courts jurisdiction, time extension, abnormal bad weather, serious loss or damage by fire or civil commotion, strike or lockout, non-availability of departmental stores, any other cause which in the absolute discretion of the accepting authority is beyond the contractor's desire, are also mentioned in the notice.