EOI towards empanelment for Capex Rate Contract under Category I for carrying out maintenance and low value capital jobs of mechanical civil and electrical nature at Retail Outlets and Consumer Outlets under Cochin DO of Kerala State Office
Expression of interest EOI towards empanelment for capex rate contract under category I for carrying out maintenance and low value capital jobs of mechanical, civil and electrical nature at retail outlets
AI helper
The tender is for empanelment for capex rate contracts for maintenance and low-value capital jobs at retail outlets. The contract period is up to ****, extendable for six months. The estimated quantum of work is **** lakhs including GST @18 for 3 years. Bidders must submit a bid security declaration. The offer is valid for 180 days from the technical bid opening date. The last date for submission of the tender is 01. 04. 2026. The court of jurisdiction for disputes up to the stage of the Letter of Acceptance (LOA) is Chennai, and for disputes after LOA and during the execution stage, it is Cochin.
The time limit for completion of every individual work shall be given by the respective divisional office of Kerala State Office at the time of award of an individual callup work order. The completion time will vary as per the scope of work included in the call up order.
The payment terms are not explicitly stated in the provided text.
There is no price bid in this tender. The documents submitted by all the bidders shall be scrutinized with respect to submission of emd bid security declaration, pqc, and other commercial criteria, acceptance to all terms conditions as per the tender.
The intending tenderers shall have to furnish proof of their criteria pqc: prequalification and experience along with the parti technocommercial bid. The annual turnover must be a minimum of Rs. 6 lakhs per divisional office during any of the immediate three preceding financial years from the date of NIT publication.
In case of price adjustment for delay in completion of the work beyond the time limit specified in the call up orders, compensation as per clause **** general conditions of contract shall be recoverable @of the callup order value per week or part thereof subject to a maximum recovery of 10 of the call up order value.
Bidders are advised to inspect the site and ascertain the site conditions including leads lifts involved approach to vehicles etc prior to quoting the amount.
The total estimated quantum of work is: **** lakhs including GST @18 for 3 years.
The tender is for the development of a new RO at Yerrapahadv, Kamareddy district, Telangana. The estimated value is ?80,42,758. 44. The tender uses a two-bid system. The offer shall be valid for 180 days from the date of opening of the technical bid. Work completion is 16 weeks from the 10th day from the date of issue of time commencement order or actual handing over of the site whichever is earlier. Bidders must submit the bid security declaration in lieu of EMD. The court of jurisdiction for all matters under the tender shall be at Chennai for disputes up to the stage of the letter of intent and at Hyderabad for disputes after the letter of intent and during the execution stage.
The bid notice states work completion : 16 weeks from the 10th day from the date of issue of time commencement order or actual handing over of the site whichever is earlier.
The bid notice states among all qualified bids, the lowest bid, with or without negotiations, as the case may be, shall be termed as l1.
The bid notice states estimated value 80, 42, **** inclusive of gst @18 of work
Development of New Retail Outlet ( CFS) at Survey Number 77/2, Phoolbagh, Solipi Somarajupeta Village, Gurla Mandal, Vizianagaram District, under Visakhapatnam Divisional Office of TAPSO
development of new ro cfs outlet at page sy. no. 772, at phoolbagh solipi somarajupetav, gurlam, vizianagaram dist, under vishakapatnam divisional office, of tapso.
AI helper
The tender is for the development of a new retail outlet CFS. The completion period is 16 weeks from the date of commencement. The bid submission end date is **** 04:45 pm and the bid opening date is **** 04:45 pm. The tender requires the submission of various documents as per the annexures. The initial security deposit is 10% of the total contract value. The court of jurisdiction for all matters under the tender shall be at chennai.
The bid notice states that he completion period shall be 16 sixteen weeks from the date of commencement.
The bid notice states that all the works carried out by the contractor shall be covered under defect liability period for a period of 12 twelve months from the date of completion.
The bid notice states that among all qualified bids, the lowest bid, with or without negotiations, as the case may be, shall be termed as l1.
The bid notice states that the estimated value is 67, 07, ****.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Sign up and receive by email
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/UTs, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits (1029 real users, 03/04/2026).Methodology
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
It's an extremely useful tool.
M. M. Alv
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
It is complete and optimal, it improves my time.
R. de L. Cruz
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
The platform is very user-friendly.
N. Lobato
I’ve landed several contracts through this platform. There’s no need to search—they send the service notifications directly to you.
A. O. Scholl
Efficiency in search times.
R. Chavez
I’m notified immediately about every tender that opens in my area. It really helps my work.
E. Goncalves
Very good — I find exactly what I’m looking for. It’s a great experience.
BidHits is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and you won't be charged automatically.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals daily at the central (Union), state, and municipal levels. Tenders are added as soon as they are published on the source portal.
Plans start at ₹ 3,900.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits. Start by adding a few key words. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1029 active users, conducted through 03/04/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
