Department Of Water Resources- Department Of Water Resources- Canal - Canal Div - Faridkot - Agency Tenders

The bid notice states he approximate time for completion of the work will be 45 days as desired by executive engineercumengineerincharge after the date of issue of work order or acceptance letter to the contractor.

The bid notice states payments of work done shall be released on receipt of funds from the government of punjabrealisation of loc from the concerned treasury and no interest claim will be entertained on delayed payments.

The bid notice states defect liability period : i. for earth work : 42 days 6 weeks ii. for all other works : 365 days

The bid notice states only those contractors shall be eligible who are registered with punjab water resources, department and have deposited the requisite licensing fee.

The bid notice states he engineer in charge of the work reserves the option to take any item of work or any part thereof at any time during the currency of the work order and reallot it to any other agency with due notice to the contractor without liability of any kind of payment or compensation.

The bid notice states before filling this tender the contractor can see the detailed drawings and specifications in the office of the faridkot canal and ground water division, on any working day during working hours and shall visit the site and satisfy as 6 to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of too and plants etc. accommodation and movement of labour,

The bid notice states ender value in inr 1, 28, 07, 000

The bid notice states that the time limit for completion is 21 days.

The document states that the award criteria are in section 28.

The invitation for bids is open to established and reputed contracting agencies who fulfill the requirements laid down in clause 4. 3 of ITB.

The estimated value of the project is 14,51,243.

The approximate time for completion of the work will be 45 days after the date of issue of work order or acceptance letter to the contractor. he approximate time for completion of the work will be 45 days as desired by 9 executive engineercumengineerincharge after the date of issue of work order or acceptance letter to the contractor.

Payments of work done shall be released on receipt of funds from the government of Punjab and no interest claim will be entertained on delayed payments. payments of work done shall be released on receipt of funds from the government of punjabrealisation of loc from the concerned treasury and no interest claim will be entertained on delayed payments.

The final acceptance of the tenders or part of the same lies with the competent authority who does not bind himself to accept the lowest or any other tender without assigning any reason for the same. he final acceptance of the tenders or part of the same lies with the competent authority who does not bind himself to accept the lowest or any other tender without assigning any reason for the same.

Only those contractors shall be eligible who are registered with Punjab Water Resources, Department and have deposited the requisite licensing fee. only those contractors shall be eligible who are registered with punjab water resources, department and have deposited the requisite licensing fee.

If the contractor is aggrieved by non payment of contract money in lieu of the workpart of work executed by him or is aggrieved by delay in payment due to him for any reason whatsoever, he will approach the concerned executive engineer who shall refer the matter to the arbitrator appointed under provisions of arbitration act within 15 days from the receipt of such representation. if the contractor is aggrieved by non payment of contract money in lieu of the workpart of work executed by him or is aggrieved by delay in payment due to him for any reason whatsoever, he will approach the concerned executive engineer who shall refer the matter to the arbitrator appointed under provisions of arbitration act within 15 days from the receipt of such representation.

Before filling this tender the contractor can see the detailed drawings and specifications in the office of the faridkot canal and ground water division, on any working day during working hours and shall visit the site and satisfy as to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of too and plants etc. before filling this tender the contractor can see the detailed drawings and specifications in the office of the faridkot canal and ground water division, on any working day during working hours and shall visit the site and satisfy as to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of too and plants etc.

The estimated cost is Rs. 3,01,902. estimate for maintenance of artificial recharge structures at cheeda rest house under faridkot canal and groundwater division, faridkot rs. 3, 01, 902

The approximate time for completion of the work will be 45 days as desired by the engineer after the date of issue of work order or acceptance letter to the contractor.

Payments of work done shall be released on receipt of funds from the government of Punjab and no interest claim will be entertained on delayed payments.

The final acceptance of the tenders or part of the same lies with the competent authority who does not bind himself to accept the lowest or any other tender without assigning any reason for the same.

Only those contractors shall be eligible who are registered with Punjab water resources, department and have deposited the requisite licensing fee.

If the contractor is aggrieved by non payment of contract money in lieu of the workpart of work executed by him or is aggrieved by delay in payment due to him for any reason whatsoever, he will approach the concerned executive engineer who shall refer the matter to the arbitrator appointed under provisions of arbitration act within 15 days from the receipt of such representation.

Before filling this tender the contractor can see the detailed drawings and specifications in the office of the faridkot canal and ground water division, on any working day during working hours and shall visit the site and satisfy as to the conditions prevalent there especially regarding accessibility to the site, nature and extent of the ground, working conditions, stacking of materials, installations of too and plants etc. accommodation and movement of labour.

The tender value is 78,23,077.