Beautification and repair work in Anand Park Ward No 15 MC Panipat For L and C Society
AI helper
The tender is for the beautification and repair work in Anand Park, Ward No. 15, MC Panipat. The estimated cost of work is rs **** lakhs. The last date for receiving bids online is **** up to 12:00 hrs. The technical qualification part of the bids will be opened online at municipal corporation panipat on **** at 03:00 hrs. Bidders must pay an e-service fee of **** are valid for 120 days from the bid closing date. The technical bid will be opened on **** at 03:00 hrs. The financial bid will be opened after the technical evaluation. The site visit is encouraged. The employer is ramesh kumar bagri, chief engineer. The engineer is gopal kalawat, executive engineer. The intended completion date is 6 months. The jurisdiction of the court is panipat. The average annual financial turnover amount is rs. eight lacs sixteen thousand. The value of work is as under : ithreeworks: **** lacs, iitwoworks: **** lacs, iiisinglework: **** lacs. Joint ventures are not allowed. The contact person is: executive engineer, gopal kalawat. The place, time and date for pre bid meeting are not applicable. The bid validity is 120 days. The defect liabilitycummaintenance period is **** days. The amount to be withheld for failing to supply asbuiltdrawings by the date required is rs. 0. 5 of agreement amount. The following events shall also be compensation events: substantially adverse ground conditions encountered during the course of execution of work not provided for in the bidding document, removal of underground utilities detected subsequently, significant change in classification of soil requiring additional mobilization by the contractor, removal of unsuitable material like marsh, debris dumps, etc not caused by the contractor, artesian conditions, seepage, erosion, landslide, river training requiring protection of permanent work, presence of historical, archeological or religious structures, monuments interfering with the works, restriction of access to ground imposed by civil, judicial, or military authority. The formula for price adjustment of prices are: adjustment of price for bitumen, adjustment for grey cement opcppc and, steel for reinforcement and structural members index for ms long products, adjustment of pol fuel and lubricant component. The retention money shall be 6 from each bill subject to a maximum of 5 of final contract price. The milestones to be achieved during the contract period are: financial works to be completed period from the start date, milestone 1 i. e. 20 25 of the stipulated time, milestone 2 i. e. 50 50 of the stipulated time, milestone 3 i. e. 75 75 of the stipulated time, milestone 4 i. e. 100 100 of the stipulated time. The amount of liquidated damages for whole of work for delay in completion of works is 12000th of the initial revised contract price, rounded off to the nearest thousand, per day. For non achievement of milestone, 12000th of the initial revised contract price, rounded off to the nearest thousand, per day. The maximum limit of liquidated damages for completion of work is 10 ten per cent of the contract price rounded off to nearest thousand. The amounts of the advance payment are: mobilization, secured advance, machinery advance. The period for setting up a field laboratory with the prescribed equipment is 28 days from the date of notice to start work. The following events shall also be fundamental breach of contract: the contractor has contravened clause 7. 1 or clause 9 of part i general conditions of contract. The percentage to apply to the value of the work not completed representing the employers additional cost for completing the works shall be 20 twenty percent.
The works must be completed within 6 months. cost of work rs **** lakhs time limit 6 months
Payments shall be adjusted for deductions for advance payments, security depositretention, other recoveries in terms of the contract and taxes at source, as applicable under the law. payments shall be adjusted for deductions for advance payments, security depositretention, other recoveries in terms of the contract and taxes at source, as applicable under the law.
The defect liabilitycummaintenance period is **** days from the date of completion. he defect liabilitycummaintenance period is **** days from the date of completion.
The contract will be awarded to the bidder whose bid has been determined to be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price. he employer will award the contract to the bidder whose bid has been determined: ito be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price
To qualify for award of the contract, each bidder in its name should have : iminimumaverageannualfinancialturnoverascertifiedbythechartered accountant during the last three years, ending 31st march of the previous financial year, should not be less than 30 of the value of work. o qualify for award of the contract, each bidder in its name should have : iminimumaverageannualfinancialturnoverascertifiedbythechartered accountant during the last three years, ending 31st march of the previous financial year, should not be less than 30 of the value of work.
In the event of failure on part of the contractor to achieve timely completion of the project, he shall pay liquidated damages to the employer at the rate per day or part thereof as stated in the contract data. in the event of failure on part of the contractor to achieve timely completion of the project, including any extension of time granted under clause 27, he shall, without prejudice to any other right or remedy available under the law to the employer on account of such breach, pay as agreed liquidated damages to the employer and not by way of penalty in a sum calculated at the rate per day or part thereof as stated in the contract data.
The bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works and its surroundings and obtain all information that may be necessary for preparing the bid and entering into a contract for construction of the works. he bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works and its surroundings and obtain all information that may be necessary for preparing the bid and entering into a contract for construction of the works.
The estimated cost of work is rs **** lakhs. cost of work rs **** lakhs
