The Governor of Haryana invites bids for the Vertical Drainage Project in Village Anwali. The work includes excavation, laying pipes, and construction of related structures. Bids must be submitted online by October 27, 2025, and will be opened on October 28, 2025. Bidders must pay an e-service fee and are encouraged to register on the Haryana Engineering Works portal. The project has a 16-month time limit. The technical qualification part of the bids will be opened online at assistant soil conservation officer sonepat on **** at 02: 00 hrs. Bids are valid for 120 days from the closing date. The employer reserves the right to reject any or all bids. The jurisdiction of the court will be as defined in the appendix to itb. The prebid meeting will be held as per the details in appendix to itb. The bidders may note that the works are to be carried out strictly as per the applicable laws, permits, rules and regulations.
The intended completion date for the whole of the works is 16 months after the start of work, as stated in the contract data.
Payments shall be adjusted for deductions for advance payments, security depositretention, other recoveries in terms of the contract and taxes at source, as applicable under the law.
The defect liabilitycummaintenance period is 03 year.
The employer will award the contract to the bidder whose bid has been determined to be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price.
Bidders must have valid contractors id registered on haryana engineering works portal.
In the event of failure on part of the contractor to achieve timely completion of the project, including any extension of time granted under clause 27, he shall, without prejudice to any other right or remedy available under the law to the employer on account of such breach, pay as agreed liquidated damages to the employer and not by way of penalty in a sum calculated at the rate per day or part thereof as stated in the contract data.
The bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works and its surroundings and obtain all information that may be necessary for preparing the bid and entering into a contract for construction of the works.
The tender value in inr 74,75,448.