Operation and maintenance of Horticulture machinery i. e. Tractor, Tree platform, JCBs, Truck mounted Sprinkler cum anti smog gun under Zone IV for 1 year under Municipal Corporation Gurugram
operation and maintenance of horticulture machinery i. e. tractor, tree platform, jcbs, truck mounted sprinkler cum anti smog gun under zone iv for 1 year under municipal corporation gurugram rates for helper with tree platform machines, sprinkler machines or any other work. driver of level ii category as per hkrnl wages rulesfor working on tractor, sprinkler and tree platform maintenance of tractor or 9 meter reach tree platform with vehicle, including tractorvehicle like mahendra pickuptipper, minor expenses such as tyre puncture repair, greasing of parts, brake repair, small spare parts like nuts, bolts, filters and belts, minor electrical repairs, and other incidental repairs generally occur. maintenance of tata 407, jcb, sprinkler machine truck mounted during the operation of tata 407 platform truck and jcb or truck mounted sprinkler machine, minor repairs such as tyre puncture, alignment and replacement, minor topup of engine and hydraulic oil, greasing and lubrication, brake and clutch adjustments, min
AI helper
The employer invites bids for the operation and maintenance of horticulture machinery for 1 year under municipal corporation gurugram. Bids must be submitted online by **** must pay an e-service fee. The technical qualification part of the bids will be opened online at municipal corporation gurugram on **** at 03: 00 hrs. Bids are valid for 120 days from the bid closing date. The work is reserved for cooperative labour and construction societies. The bid requires an earnest money declaration form. The site visit is encouraged. The jurisdiction of the court will be as defined in the appendix to itb. The technical qualification part of the bids will be opened online at municipal corporation gurugram on **** at 03: 00 hrs. The financial bid will be opened online for qualified bidders. The employer reserves the right to reject any or all bids without assigning any reason.
The bid notice states that the time limit is 15 months. cost of work rs **** lakhs time limit 15 months
The employer will award the contract to the bidder whose bid has been determined to be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price. he employer will award the contract to the bidder whose bid has been determined: ito be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price
Bidders must have created a contractor ID on the portal https:works. haryana. gov. in. he invitation for bids is open to all bidders have created contractor id on the portal https:works. haryana. gov. in and eligible bidders meeting the eligibility criteria as defined in itb.
The contractor will pay liquidated damages if they fail to achieve timely completion of the project. in the event of failure on part of the contractor to achieve timely completion of the project, including any extension of time granted under clause 27, he shall, without prejudice to any other right or remedy available under the law to the employer on account of such breach, pay as agreed liquidated damages to the employer and not by way of penalty in a sum calculated at the rate per day or part thereof as stated in the contract data.
The bidder is encouraged to visit and examine the site of works and its surroundings. he bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works and its surroundings and obtain all information that may be necessary for preparing the bid and entering into a contract for construction of the works.
The estimated cost of work is rs **** lakhs. cost of work rs **** lakhs
Operation and maintenance of Horticulture machinery i. e. Tractor, Tree Platform, JCBs, Truck mounted Sprinkler cum anti smog gun under Zone III for 1 year under Municipal Corporation Gurugram
operation and maintenance of horticulture machinery i. e. tractor, tree platform, jcbs, truck mounted sprinkler cum anti smog gun under zone iii for 1 year under municipal corporation gurugram rates for helper with tree platform machines, sprinkler machines or any other work, driver of level ii category as per hkrnl wages rulesfor working on tractor, sprinkler and tree platform, maintenance of tractor or 9 meter reach tree platform with vehicle, including tractorvehicle like mahendra pickuptipper, minor expenses such as tyre puncture repair, greasing of parts, brake repair, small spare parts like nuts, bolts, filters and belts, minor electrical repairs, and other incidental repairs generally occur, maintenance of tata 407, jcb, sprinkler machine truck mounted during the operation of tata 407 platform truck and jcb or truck mounted sprinkler machine, minor repairs such as tyre puncture, alignment and replacement, minor topup of engine and hydraulic oil, greasing and lubrication, brake and clutch adjustments, m
AI helper
The tender is for the operation and maintenance of horticulture machinery in Gurugram for 1 year. Bids must be submitted online by 09/10/2025. A fee of ?5,000 is required, along with an EMD of ?1,58,042. The technical bids will be opened on 09/10/2025 at 03:00 hrs. The work duration is 15 months. Bidders must register on the works. haryana. gov. in portal. Online submission of bids is mandatory. The bid validity is 120 days. The site visit is encouraged. The employer is the Commissioner, Municipal Corporation, Gurgaon. The engineer is Sandeep Kumar, Executive Engineer. The contract includes price adjustments for bitumen, cement, steel, and fuel. The defect liability period is 180 days.
The work must be completed within 15 months. he intended completion date for the whole of the works is 15 months after start of work.
Payments will be made according to the actual work done by the contractor. he payment will be made according to the actual work done by the contractor.
The defect liabilitycummaintenance period is 180 days from the date of completion. he defect liabilitycummaintenance period is 180 days from the date of completion.
The contract will be awarded to the bidder whose bid has been determined to be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price. he employer will award the contract to the bidder whose bid has been determined: ito be substantially responsive to the bidding documents and who has offered the lowest evaluated bid price
Bidders must be registered on the works. haryana. gov. in portal. interested bidders are encouraged to get themselves registered as contractor on the portal https:works. haryana. gov. in.
In the event of failure on part of the contractor to achieve timely completion of the project, he shall pay liquidated damages. in the event of failure on part of the contractor to achieve timely completion of the project, including any extension of time granted under clause 27, he shall, without prejudice to any other right or remedy available under the law to the employer on account of such breach, pay as agreed liquidated damages to the employer and not by way of penalty in a sum calculated at the rate per day or part thereof as stated in the contract data.
The bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works. he bidder, at the bidders own responsibility and risk is encouraged to visit and examine the site of works and its surroundings and obtain all information that may be necessary for preparing the bid and entering into a contract for construction of the works.
The tender value is ?79,02,****. ender value in inr 79, 02, 120
Material for replacement of Engine Oil SAE 15 W, Material for topup of gear oil SAE 85W- 140 complete, Material for topup of clutch oil SAE 80W- 90 complete, Material for topup of coolant complete, Material for replacement of fuel filter complete, Material for replacement of oil filter complete, Material for repplacement air filter complete, Material and Labour for sheet cover with cushion complete, Material for BS6 engine diesel exhast fluid
Material for replacement of Engine Oil SAE 15 W- 40 complete, Material for topup of gear oil SAE 85W- 140 complete, Material for topup of clutch oil SAE 80W- 90 complete, Material for topup of coolant complete, Material for replacement of fuel filter complete, Material for replacement of oil filter complete, Material for repplacement air filter complete, Material and Labour for sheet cover with cushion complete, Material for BS6 engine diesel exhast fluid blacket DEF Urra blacket close complete
Preventive maintenance oil topup and cleaning of plants machines at BHEL Jhansi Preventive maintenance of type a plants 28 machines, Preventive maintenance of type b plants 62 machines, Preventive maintenance of type c plants 146 machines, oil topup and cleaning of machines 12 cycles
AI helper
The tender is for preventive maintenance, oil top-up, and cleaning of plants and machines at BHEL Jhansi for one year. The last date for receipt of the tender is **** at 13:15 hrs. The tender opening date is **** at 14:00 hrs. Bidders must submit an earnest money deposit (EMD) of Rs. 47,280. The tender document includes details of qualifying requirements, technical bid, price schedule, and general terms and conditions. Reverse auction is applicable. A mandatory preliminary visit to the work place is allowed before the last date for submission of tenders. Penalties are defined for delay in starting or completing the work, and for non-completion of oil top-up. The minimum staff requirement is 1 supervisor, 1 electrician, 1 fitter, and 6 helpers. The bidder must provide audited balance sheets and profit and loss accounts for the last three financial years, or a CA certificate. The bidder must have experience of executing similar works during the last 7 years. All works have to be carried out in BHEL premises. BHEL will provide electric supply, eot cranes, trolley/truck for material handling as and when required. No accommodation facility will be provided by BHEL.
The bid should be submitted by 13:15 hrs on the due date.
The L1 bidder will be decided based on the D3 rate.
The bidder should have an average annual financial turnover of at least Rs. 7. 09 lakhs during the last 3 years ending 31st March 2025. Bidder should have experience of executed similar work during last 7 years ending the month previous to the month of issuing tender enquiry.
Late start of preventive contract or non-completion of work will attract a deduction of 0. 5% per week of the total contract value, subject to a maximum deduction of 10% of the contract value. Additional penalty for non-completion of preventive maintenance of machines will be as per actual work order rate of machine type A or B or C. Penalty for non-completion of oil top-up will be equal to 1 sub-cycle for each cycle.
The contractors may physically visit the work place before quoting their rates.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Sign up and receive by email
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/UTs, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits (1029 real users, 03/04/2026).Methodology
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
It encompasses all portals in one place.
G. Ferrea
It's an extremely useful tool.
M. M. Alv
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
It is complete and optimal, it improves my time.
R. de L. Cruz
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
The platform is very user-friendly.
N. Lobato
I’ve landed several contracts through this platform. There’s no need to search—they send the service notifications directly to you.
A. O. Scholl
Efficiency in search times.
R. Chavez
I’m notified immediately about every tender that opens in my area. It really helps my work.
E. Goncalves
Very good — I find exactly what I’m looking for. It’s a great experience.
BidHits is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and you won't be charged automatically.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals daily at the central (Union), state, and municipal levels. Tenders are added as soon as they are published on the source portal.
Plans start at ₹ 3,900.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits. Start by adding a few key words. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1029 active users, conducted through 03/04/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
