Supply for Three Clerk Cum Computeroperator in Mc Dera Baba Nanak
AI helper
The tender requires registration on eproc. punjab. gov. in, digital signature, and earnest money via epayment. The cost of the tender form is Rs. 500. The tender validity is 180 days. EMD and tender form fees are payable to Municipal Council, Dera Baba Nanak online. Bidders must be enlisted with the Municipal Council or other government departments. Corrigendum/modifications will be posted on the website. The work will be executed according to form MW4 and Punjab PWD specifications. The final payment will be based on the overall lowest statement. The arbitrator for disputes is the additional deputy commissioner, Pathankot. GST, income tax, EPF, and other taxes will be deducted from the contractor's bill. The contractor must have a PAN card and GST registration number. ESI and EPF certificates must be uploaded. The agency must upload a self-declaration of not being blacklisted. The contractor must submit an undertaking that the sum total of works being bid does not exceed their bid capacity. For supply items, bidders should be manufacturers or authorized dealers. The contractor must submit the work done bill for payment. Payment for supply of materials shall only be made after verification of original bills and testing reports. The contractor is bound to comply with any instruction issued by the government from time to time. Substandard materials will be rejected. The goods bearing the ISI mark or the approval make will be the minimum standard. The work supply orders for the development works and supply of various items will be issued only according to availability of funds/government grant and priority of works. The comparative statement shall be as per the quoted rates. The rates of the items mentioned in the estimates will be paid as per rates mentioned in latest CSR and AC slips prevailing at the time of opening of the tenders. The technical and financial bids must be submitted separately. The technical bid will be opened only if a minimum of three bidders participate in the e-tendering process. The president and E. O. of the Municipal Council have the right to accept or reject any or all tenders without assigning any reason. The contractor shall produce a certificate from the manufacturer that interlocking paver blocks for the specified/allotted work have been supplied by him and the grade of the paver blocks is per **** paver blocks should be ISI marked. The contractor shall have to submit his work done bill for payment. Payment for supply of materials shall only be made after verification of original bills and testing reports. In concrete works, only ready mix concrete will be allowed within a 40 km range. All the works will be completed within the stipulated time as per mentioned in the NIT. If the contractor will not do so then the penalty will be charged as per the department/govt. instructions. Regarding supply of electric material, bidder should be authorized dealer of Crompton and Bajaj. Cable should be ISI branded. The payment of work done will be made only after the receiving the test report from NABL approved labs/engineering colleges/govt. laboratories.
The notice states that all the works will be completed within the stipulated time as per mentioned in the nit.
The notice states that payment for supply of materials shall only be made after verification of original bills and testing reports.
The notice states that after the completion of work, in case any damage occurs within three years then the cost of repair will be beard by contractoragency.
The notice states that he final payment will be made to the contractor on the basis of the overall lowest statement as worked out in the final stage.
The notice states that for participating in the above etendering process, the contractors shall have to get themselves registered with eproc. punjab. gov. inand get user id and password.
The notice states that if the contractor will not do so then the penalty will be charged as per the department/govt. instructions.
The notice states that the estimated cost is ****.
P/L Interlocking tiles from Main Bazar to Punjab and Sind Bank DBN W. No. 9
Sale of bid documents for p/l interlocking tiles from house of shamsher singh to corridor, rasta shamshan ghat pakhoke near dhussi, interlocking tiles and boundry wall in jaurian khurd ward, pvc pipe, const. of road galli in street gurdial singh niwas, interlocking tiles in street house of gurdip singh, mehal, interlocking tiles from main bazar to punjab & sind bank p/l interlocking tiles from house of shamsher singh to corridor road ward no. 7 jaurian khurd, p/l interlocking tiles rasta shamshan ghat pakhoke near dhussi bann, p/l interlocking tiles and boundry wall in jaurian khurd ward number 7, p/l pvc pipe , const. of road galli in street gurdial singh niwas ward number 7 jaurian khurd, p/l interlocking tiles in street house of gurdip singh , mehal singh near noor tent house and near dingi pulli jaurian khurd, p/l interlocking tiles from main bazar to punjab & sind bank dbn w. no. 9
AI helper
The tender is for various works in Dera Baba Nanak, Punjab. Bidders must register on eproc. punjab. gov. in and have a digital signature. Earnest money is required in the form of e-payment. Tender form fee is Rs. 500. Bidders must be enlisted as civil contractors, building contractors, or road works contractors with the municipal council or other government departments. Specific requirements exist for electrical works. The tender validity is 180 days. The tender will be opened on the next working day if the scheduled date is a holiday. The work will be executed according to the provisions in form mw4 and Punjab PWD specifications. A dispute resolution process is outlined, including arbitration. Quoted tenders must be as per approved class. GST, income tax, EPF, and other taxes will be deducted from the contractor's bill. Bidders must have PAN card, GST registration, ESI number certificate, EPF number certificate, and a self-declaration that they are not blacklisted. L&C society members must provide certified identity cards and a resolution. Bidders must submit an undertaking that the total value of works does not exceed their capacity. For supply items, bidders must be manufacturers or authorized dealers. Security will be deducted from each bill. Conditional/improper/unbalanced tenders will not be accepted. Scanned copies of all **** are required. Rates should be quoted in figures and words. Technical and financial bids must be submitted separately. Minimum three bidders are required for technical bid opening. The president and executive officer of the municipal council have the right to accept or reject any or all tenders. The quantity and scope of work may be increased or decreased. No claims will be entertained in this regard. If any document is found false, fraud, or fake, action will be taken accordingly. No agency will sublet the development work. The contractor will produce a photograph before and after the work. Only ready-mix concrete will be allowed in concrete works. All works must be completed within the stipulated time. Penalties will be charged if not completed on time. For supply of employees/manpower, EPF must be deposited every month. For supply of electric material, bidders should be authorized dealers of Crompton and Bajaj. Cable should be ISI branded. Payment will be made only after receiving test reports from NABL approved labs. Labour and construction society will deposit earnest money as per government guidelines. The rates of items will be paid as per the latest CSR and A&C slips. Analysis of rates can be seen in the municipal council office. Internet accessibility/technical assistance issues may delay the opening of technical and financial bids. Bidders are responsible for any clerical mistakes. The work/supply orders will be issued according to the availability of funds/government grant and priority of works. Substandard materials will be rejected. Display of an informatory board is compulsory on the work site. The goods bearing the ISI mark will be the minimum standard. FOB will be at the municipal council/nagar panchayat.
P/L Interlocking tiles in street house of Gurdip Singh , Mehal singh near noor tenthouse and near dingi pulli jaurian khurd
Sale of bid documents for p/l interlocking tiles in street house of gurdip singh, mehal singh near noor tent house and near dingi pulli jaurian khurd p/l interlocking tiles from house of shamsher singh to corridor road ward no. 7 jaurian khurd, p/l interlocking tiles rasta shamshan ghat pakhoke near dhussi bann, p/l interlocking tiles and boundry wall in jaurian khurd ward number 7, p/l pvc pipe, const. of road galli in street gurdial singh niwas ward number 7 jaurian khurd, p/l interlocking tiles in street house of gurdip singh, mehal singh near noor tent house and near dingi pulli jaurian khurd, p/l interlocking tiles from main bazar to punjab & sind bank dbn w. no. 9
AI helper
The tender is for various construction works, including interlocking tiles, PVC pipes, and road construction in Dera Baba Nanak. Bidders must register on eproc. punjab. gov. in, have a digital signature, and pay a tender form fee of INR 500 and earnest money. Participation criteria include enlistment as a civil contractor/building contractor/road works contractor with the municipal council or other government departments. Specific requirements exist for electrical works, and the tender validity is 180 days. The tender will be opened on 15/07/2025 at 10:00 AM for technical bids and 12:00 PM for financial bids. Detailed terms and conditions, including dispute resolution, are available on the website. The tender documents are available for download from 01/07/2025 at 03:00 PM to 14/07/2025 at 05:00 PM. Additional documents, such as PAN card, GST registration, ESI, EPF certificates, and a self-declaration of no blacklisting, are required. L&C society members must provide certified identity cards and resolutions. The contractor must comply with all government instructions and specifications. The work will be executed according to the provisions of form MW4 and Punjab PWD/MORTH specifications. The payment will be made based on the lowest overall statement. Conditional/improper/unbalanced tenders will not be accepted. The contractor will be responsible for any damage within three years of completion. Substandard materials will be rejected. Display of an informatory board on the work site is mandatory. The work will be executed according to the availability of funds/government grant and priority of works. The rates of items will be paid as per the latest CSR and A&C slips. The analysis of rates can be seen in the municipal council office. The opening of technical and financial bids may be delayed due to internet accessibility/technical assistance issues. The tenderer must be a manufacturer or authorized dealer for supply items. The contractor must produce a certificate from the manufacturer that the interlocking paver blocks meet IS **** standards. For concrete works, only ready-mix concrete will be allowed within a 40 km range. All works must be completed within the stipulated time, otherwise penalties will apply. For supply of employees/manpower, the contractor must deposit EPF every month. For supply of electric materials, the bidder should be an authorized dealer of Crompton and Bajaj, and cables should be ISI branded. Payment will be made only after receiving test reports from NABL-approved labs/engineering colleges/government laboratories. No agency will sublet the development work after the work order. The NIT shall be a part of the agreement. The contractor will produce a photograph before starting and completing the work.
P/L PVC Pipe , Const. of road galli in street gurdial singh niwas ward number 7 jaurian khurd
Sale of bid documents for p/l pvc pipe, const. of road galli in street gurdial singh niwas ward number 7 jaurian khurd p/l interlocking tiles from house of shamsher singh to corridor road ward no. 7 jaurian khurd, p/l interlocking tiles rasta shamshan ghat pakhoke near dhussi bann, p/l interlocking tiles and boundry wall in jaurian khurd ward number 7, p/l pvc pipe , const. of road galli in street gurdial singh niwas ward number 7 jaurian khurd, p/l interlocking tiles in street house of gurdip singh , mehal singh near noor tent house and near dingi pulli jaurian khurd, p/l interlocking tiles from main bazar to punjab & sind bank
AI helper
The municipal council of Dera Baba Nanak is issuing a tender for various works, including road construction, interlocking tiles, and PVC pipe installation. Bidders must register on eproc. punjab. gov. in, have a digital signature, and pay a tender form fee of INR 500 and earnest money. The tender closing date is 14/07/2025 5. 00 pm. The technical bid opening date is 15/07/2025 **** am, and the financial bid opening date is 15/07/2025 **** pm. Detailed terms and conditions, including participation criteria, dispute resolution, and required documents (e. g. , PAN card, GST registration, ESI/EPF certificates, latest self-declaration, and capacity certificate), are available on the website. The validity of the tender is 180 days. The work will be executed according to the provisions of form MW4 and Punjab PWD/MORTH specifications. The payment will be made based on the lowest overall statement. The tender will be considered only if accompanied by earnest money in the form of e-payment. The tenderer must be enlisted with the municipal council or a government department as a civil contractor/building contractor/road works contractor. For electrical works, the tenderer must be enlisted as an electrical contractor and have a license from the Chief Electrical Inspector, Patiala. The quoted tender should be as per the approved class by the individual contractor/cooperative society. Substandard materials will be rejected. The work must be completed within the stipulated time, and penalties may apply for delays. Payment for supply of materials will be made after verification of original bills and testing reports. The contractor will be responsible for any damage within three years of completion. The comparative statement will be based on quoted rates. The rates of items will be paid as per the latest CSR and A&C slips prevailing at the time of opening of the tenders. The analysis of rates can be seen in the municipal council office. The opening of technical and financial bids may be delayed due to internet accessibility issues. The president and executive officer of the municipal council have the right to accept or reject any or all tenders without assigning any reason. The estimate quantity and scope of work can be increased/decreased or changed as per the site condition. No agency will sublet the development work after work order. The NIT shall be a part of the agreement. The contractor will produce a photograph before the start of the work and completion of the work. In concrete works, only ready mix concrete will be allowed within a 40 km range. For supply of employees/manpower, the contractor will be bound to deposit the EPF of the employees every month and submit the EPF challans before the last date of every month. Regarding supply of electric material, bidder should be authorized dealer of Crompton and Bajaj. Cable should be ISI branded. The payment of work done will be made only after receiving the test report from NABL approved labs/engineering colleges/government laboratories. No extra payment will be made for test reports. Labour and construction societies will deposit earnest money as per government guidelines.
P/L Interlocking tiles and boundry wall in jaurian khurd ward number 7
Sale of bid documents for p/l interlocking tiles and boundry wall in jaurian khurd ward number 7 p/l interlocking tiles from house of shamsher singh to corridor, road ward no. 7 jaurian khurd, p/l interlocking tiles rasta shamshan ghat pakhoke near dhussi, p/l interlocking tiles and boundry wall in jaurian khurd ward 26, p/l pvc pipe , const. of road galli in street gurdial singh niwas, p/l interlocking tiles in street house of gurdip singh, mehal, p/l interlocking tiles from main bazar to punjab & sind bank
AI helper
The municipal council of Dera Baba Nanak is inviting bids for the construction of p/l interlocking tiles and boundary wall in Jaurian Khurd ward number 7. Bid documents are available from 01/07/2025 **** am to 14/07/2025 5. 00 pm. The technical bid opening is scheduled for 15/07/2025 **** am, and the financial bid opening is scheduled for 15/07/2025 **** pm. Bidders must register on eproc. punjab. gov. in, have a digital signature, and pay a tender form fee of Rs. 500/- and earnest money. Detailed terms and conditions, including eligibility criteria, are available on the website. The tender validity is 180 days. The tender will be considered only if accompanied by earnest money in the form of e-payment. The work will be executed according to the provisions contained in form mw4 and Punjab pwd specifications/morth specifications. The final payment will be made based on the overall lowest statement. In case of disputes, additional deputy commisioner(g),pathankot will be the arbitrator. Quoted tenders should be as per approved class by the individual contractor/co-op society. GST, income tax, EPF and other taxes will be deducted from the contractor's bill. The contractor/agency/firm must have PAN card number, GST registration number, ESI number certificate, EPF number certificate, and a self-declaration that the agency has not been blacklisted. L&C co-op societies must upload the latest capacity certificate issued by the asstt. registrar/registrar co-op society. Intending bidders shall submit an undertaking that the sum total of works being bid does not exceed their bid capacity. For works related to supply of items, the bidders should be manufacturer or authorized dealer. All works will be completed within the stipulated time. Payment for supply of materials shall only be made after verification of original bills and testing reports. Substandard materials will be rejected. Display of informatory board is compulsory on work site. The work/supply orders will be issued according to availability of funds/government grant and priority of works. The comparative statement shall be as per the quoted rates. Analysis of rates and rates mentioned in estimates can be seen in the municipal council/nagar panchayat office. Bidders are responsible for any clerical mistakes. Technical and financial bids must be submitted separately. The technical bid of contractors/agencies/firms/co-op societies will be opened only if minimum three bidders participate. The president and executive officer of the municipal council/nagar panchayat have the right to accept/reject any or all tenders without assigning any reason. Estimate quantity and scope of work can be increased/decreased or changed as per the site condition. No agency will sublet the development work after work order. The NIT shall be a part of the agreement. In concrete works, only ready mix concrete will be allowed within 40 km range. Regarding supply of electric material, bidder should be authorized dealer of crompton and bajaj. Cable should be ISI branded. The payment of work done will be made only after receiving the test report from NABL approved labs/engineering colleges/govt. laboratories. The labour and construction society will deposit the earnest money as per the govt. guidelines/department instructions.
We selected the most helpful reviews from real users. Order may change periodically.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
Excellent information. Just what I was looking for.
L. H. Borrelli
It gives me information on tenders that interest me. It's easy to find tenders.
A. Armenta
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
I am very satisfied; it's a very useful tool.
J. S. Garcia
The system is very practical. It’s helped increase my monthly revenue.
F. H. Silva
Excellent platform to help promote and expand the reach of your work.
C. Merino
Great recommendations appear. Having the bid process link right in the email body helps a lot and saves time.
V. Kafka
It helps me identify areas of opportunity and find tenders related to my work area.
BidHits helps businesses find relevant Indian public tenders faster. We monitor official sources, show results on the site and by email, and help you open documents or the official process page.
Enter your email and activate the trial. For 14 days you can use the features, test your keywords and check the quality of matches. If you do not subscribe at /subscription.php, access becomes limited and you will not be charged automatically.
Add keywords for what you sell, start the trial, and receive matching opportunities by email. After signup, you can adjust states/UTs, delivery times and email style in Settings.
Whenever possible, yes. Some official portals require login, captcha or other access steps. In those cases, we point you to the official process page so you can continue from the correct source.
Yes. In the tenders panel you can filter by state/UT, procurement method, dates and value ranges. You can also save preferences for future alerts and searches.
Yes. You can favourite tenders, add private notes, remove what does not fit and use comments to keep your pipeline organised.
Smart Search can make mistakes, so your keywords still matter. Add specific terms, remove off-topic words and adjust your settings to improve future alerts.
Yes. You can query tenders via API. Documentation is available at /api_integration.php. It is useful for CRM, BI and internal workflows.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official sources daily at central, state and local levels. New tenders are added as soon as they are collected from the source.
Plans start at ₹ 3,900.00/month. Start with the free trial - no auto-charge.
Search a term, enable alerts, open documents or official pages, and filter by state/UT, method and value.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1054 active users, conducted through 25/05/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
