Rater e-Tenders

The tender for repairing of road and path at 220kv sstn hvpnl daultabad is open to registered labour construction coop. societies or turnkey contractors. The tender document fee is ****, non-refundable, and e-service charges are ****, non-refundable. Earnest money deposit (EMD) is Rs. 9982. The tender submission deadline is **** upto 11:00 hrs. and the bid opening date is **** at 13:00 hrs. The completion period is 120 days from the next day of issue of work order. Penalties apply for late completion. The tender documents are available online at www. ***. *. * and www. ***. *. * must provide PAN, GST, and TAN numbers. Conditional tenders are not acceptable. The tender will be valid for three months from the opening date. If the opening date is a holiday, the next working day will be considered. Only registered labour construction coop. societies or turnkey contractors with experience and a satisfactory certificate from at least executive engineer level are eligible. The detailed scope of work is in the bidding document. The activity can be increased or decreased during execution. The tenderer must mention all applicable taxes, duties, levies, cess in the quoted prices. Payment will be made through RTGS after verification. The work must be completed within 120 days from the work order issue date. Penalties apply for late completion. All statutory liabilities for wages and other dues of labor are the contractor's responsibility. Income tax and other taxes will be deducted from contractor bills. Extension in completion schedule due to non-fulfillment of obligations by the Nigam or force majeure will be considered on merits. The decision of xen400kv sstn hvpnl daultabad is final and binding. Drawings, specifications, and HVPN labor schedule rates are available in the office of xents hvpnl, Gurugram. The competent authority reserves the right to reject any or all quotations without assigning reasons. Telegraphic tenders are not acceptable. No idling charges or cost overrun will be entertained. The quantum of work may be increased or decreased. If work progress is not as expected, the remaining work may be taken over by the department. The contractor must abide by minimum wage rules. Arbitration is possible. The contractor is responsible for safety precautions and any accidents. Temporary work is the contractor's responsibility. Physical obstructions will be added to the contractor's price. The contractor must hold PAN, GST, TIN, labor license, and electrical license. HVPNL reserves the right to take supply of required items. The work must be executed on working days during working hours. Extension of time can be requested in writing within 1 day of the hindrance. The engineer-in-charge has the power to object to the employment of any workman. The contractor is liable for damage to the work. The contractor cannot assign or sublet without approval. The contractor is responsible for the conduct of the workmen. No labor below 18 or above 62 years of age shall be deployed. The contractor must execute an agreement on a non-judicial stamp paper within 7 days of the work order receipt. The draft language for the contract agreement is in annexure C. The tenderer must attach scanned copies of required documents. Failure to do so may lead to rejection. The tender must be on the prescribed form and complete. The bidder must upload technical offer, qualifying requirements, and terms and conditions (except rates) in a technical template. Prices must be quoted in the price bid format. The tender must be valid for 180 days. The period of work is 120 days. The location is Daultabad, pincode ****.